13-083.00 WM Smith & Assoc: Terrace View Park Pool Tank PaintingCONSTRUCTION AGREEMENT
W. M. Smith & Associates, Inc.
THIS CONSTRUCTIONAGREEMENT (the "Agreement ") is made by and between the City of
Spokane Valley, a code City of the State of Washington ( "City ") and W. M. Smith & Associates, Inc.,
( "Contractor ") jointly referred to as (the "Parties ").
IN CONSIDERATION of the terms and conditions contained herein the Parties agree as follows:
1. Work to Be Performed. Contractor shall do all work and furnish all labor, supervision, tools, materials,
supplies and equipment and other items necessary for the construction and completion of the Terrace View
Park Pool Tank Painting Project (the "Work ") in accordance with documents described in Exhibit 1 and in
accordance with this Agreement (which are by this reference incorporated herein and made part hereof (the
"Contract Documents ")), and shall perform any changes in the work in accordance with the Contract
Documents. The terms and provisions in this Agreement shall control over any inconsistent or incompatible
terms in any other Contract Document.
Contractor shall, for the amount set forth in paragraph 4, below, assume and be responsible for the cost and
expense of all work required for constructing and completing the Work and related activities provided for in
the Contract Documents to City's satisfaction, within the time limits prescribed in the Contract Documents.
The City Manager, or designee, shall administer and be the primary contact for Contractor. Upon notice from
City, Contractor shall promptly commence work, complete the same in a timely manner, and cure any failure in
performance under this Agreement.
Unless otherwise directed by City, all work shall be performed in conformance with the Contract Documents,
and all City, State and federal standards, codes, ordinances, regulations and laws as now existing or as may be
adopted or amended.
2. Time for Performance. Contractor shall commence the Work within 10 days of receipt of a notice to
proceed [or execution of this Agreement] and shall complete the Work within the times specified in the
Contract Documents, as may be extended in accordance with this Agreement and the Contract Documents.
3. Liquidated Damages. N /A.
4. Compensation. In consideration of Contractor performing the Work, City agrees to pay Contractor in
accordance with the Contract Documents the sum of $29,500.00, plus $2,566.50 Washington State Sales Tax,
based on the bid submitted by Contractor, and as may be adjusted in accordance with the Contract Documents.
Total project cost to be $32,066.50.
5. Payment. Contractor may elect to be paid in monthly installments, upon presentation of an application for
payment in a form satisfactory to City. Applications for payment shall be sent to the City Finance Department
at the below stated address.
Pursuant to Chapter 60.28 RCW, five percent of the compensation due Contractor shall be retained by City.
City reserves the right to withhold payment under this Agreement which is determined in the reasonable
judgment of the City Manager or designee to be noncompliant with the Contract Documents, City standards,
City Code, and federal or state standards.
Construction Agreement Page 1 of 6
6. Notice. Notice other than applications for payment shall be given in writing as follows:
TO THE CITY:
Name: Christine Bainbridge, City Clerk
Phone: (509) 921 -1000
Address: 11707 East Sprague Ave, Suite 106
Spokane Valley, WA 99206
TO THE CONTRACTOR:
Name: W. M. Smith & Associates, Inc.
Phone: 800 - 426 -9460
Address: P.O. Box 398
Ellensburg, WA 98926
7. Applicable Laws and Standards. The Parties, in the performance of this Agreement, agree to comply with
all applicable federal, state, and local laws, codes and regulations.
8. Certification Retarding Debarment, Suspension, and Other Responsibility Matters — Primary
Covered Transactions.
A. By executing this Agreement, the Consultant certifies to the best of its knowledge and belief, that it
and its principals:
1. Are not presently debarred, suspended, proposed for debarment, declared ineligible, or
voluntarily excluded from covered transactions by any federal department or agency;
2. Have not within a three -year period preceding this proposal been convicted of or had a
civil judgment rendered against them for commission or fraud or a criminal offense in
connection with obtaining, attempting to obtain, or performing a public (federal, state, or
local) transaction or contract under a public transaction; violation of federal or state antitrust
statues or commission of embezzlement, theft, forgery, bribery, falsification or destruction of
records, making false statements, or receiving stolen property;
3. Are not presently indicted for or otherwise criminally or civilly charged by a governmental
entity (federal, state, or local) with commission of any of the offenses enumerated in
paragraph (A)(2) of this certification; and
4. Have not within a 3 -year period preceding this application/proposal had one or more
public transactions (federal, state, or local) terminated for cause or default.
B. Where the prospective primary participant is unable to certify to any of the statements in this
certification, such prospective participant shall attach an explanation to this Agreement.
9. Prevailing Wales on Public Works. Contractor, any subcontractor, or other person doing work under this
Agreement, shall comply with the requirements of RCW 39.12, and shall pay each employee an amount not
less than the Prevailing Rate of Wage, as specified by the Industrial Statistician of the Washington State
Department of Labor and Industries ( "L &I "). If employing labor in a class not shown, Contractor shall request
a determination of the correct wage rate for the class and locality from the Industrial Statistician. Contractor
shall provide a copy of any such determinations to City.
Before commencing, during, and upon completion of the work, Contractor shall file all forms and pay all fees
required by L &I and shall indemnify and hold City harmless from any claims related to its failure to comply
with RCW 39.12.
The following information is provided pursuant to RCW 39.12.030:
Construction Agreement Page 2 of 6
A. State of Washington prevailing wage rates applicable to this public works project, published by
L &I are located the L &I website address:
hops: / /fortress.wa.gov /lni/wa elg ookup /prvWa el�p.aspx
B. This Project is located in Spokane County.
C. The effective prevailing wage date is the same date as the bid due date as referenced in the
original request for bids as may be revised by addenda.
A copy of the applicable prevailing wage rates is also available for viewing at the offices of City located at
11707 East Sprague, Suite 106, Spokane Valley, WA 99206. Upon request, City will mail a hard copy of the
applicable prevailing wages for this project.
10. Relationship of the Parties. It is understood, agreed and declared that Contractor shall be an independent
contractor, and not the agent or employee of City, that City is interested in only the results to be achieved, and
that the right to control the particular manner, method and means in which the services are performed is solely
within the discretion of Contractor. Any and all employees who provide services to City under this Agreement
shall be deemed employees solely of Contractor. Contractor shall be solely responsible for the conduct and
actions of all its employees under this Agreement and any liability that may attach thereto.
11. Ownership of Documents. All drawings, plans, specifications, and other related documents prepared by
Contractor under this Agreement are and shall be the property of City, and may be subject to disclosure
pursuant to RCW 42.56 or other applicable public record laws.
12. Records. The City or State Auditor or any of their representatives shall have full access to and the right to
examine during normal business hours all of Contractor's records with respect to all matters covered in this
Agreement. Such representatives shall be permitted to audit, examine and make excerpts or transcripts from
such records and to make audits of all contracts, invoices, materials, payrolls and record of matters covered by
this contract for a period of three years from the date final payment is made hereunder.
13. Warrantv. Unless provided otherwise in the Contract Documents, Contractor warrants that all Work and
materials performed or installed under this Agreement are free from defect or failure for a period of one year
following final acceptance by City, unless a supplier or manufacturer has a warranty for a greater period, which
warranty shall be assigned or transferred to City. In the event a defect or failure occurs in work or materials,
Contractor shall, within the warranty period, remedy the same at no cost or expense to City. This warranty
provision shall not be construed to establish a period of limitation with respect to Contractor's other obligations
under this Agreement.
14. Contractor to Be Licensed And Bonded. Contractor shall be duly licensed, registered and bonded by the
State of Washington at all times this Agreement is in effect.
15. Insurance. Contractor shall procure and maintain for the duration of the Agreement, insurance against
claims for injuries to persons or damage to property which may arise from or in connection with the
performance of the work hereunder by Contractor, its agents, representatives, or employees.
A. Minimum Scope of Insurance. Contractor shall obtain insurance of the types described below:
1. Automobile liability insurance covering all owned, non - owned, hired, and leased vehicles.
Coverage shall be written on Insurance Services Office (ISO) form CA 00 01 or a substitute
Construction Agreement Page 3 of 6
form providing equivalent liability coverage. If necessary, the policy shall be endorsed to
provide contractual liability coverage.
2. Commercial general liability insurance shall be written on ISO occurrence form CG 00 01
and shall cover liability arising from premises, operations, independent contractors, products -
completed operations, stop gap liability, personal injury and advertising injury, and liability
assumed under an insured contract. The commercial general liability insurance shall be
endorsed to provide the Aggregate Per Project Endorsement ISO form CG 25 03 11 85.
There shall be no endorsement or modification of the commercial general liability insurance
for liability arising from explosion, collapse or underground property damage. City shall be
named as an insured under Contractor's commercial general liability insurance policy with
respect to the work performed for City using ISO Additional Insured endorsement CG 2010
10 01 and Additional Insured- Completed Operations endorsement CG 20 37 10 01 or
substitute endorsements providing equivalent coverage.
3. Workers' compensation coverage as required by the industrial insurance laws of the State
of Washington.
B. Minimum Amounts of Insurance. Contractor shall maintain the following insurance limits:
1. Automobile liability insurance with a minimum combined single limit for bodily injury and
property damage of $1,000,000 per accident.
2. Commercial general liability insurance shall be written with limits no less than $1,000,000
each occurrence, $2,000,000 general aggregate, and a $2,000,000 products - completed
operations aggregate limit.
C. Other Insurance Provisions. The insurance policies are to contain, or be endorsed to contain, the
following provisions for automobile liability, professional liability and commercial general liability
insurance:
1. Contractor's insurance coverage shall be primary insurance with respect to City. Any
insurance, self - insurance, or insurance pool coverage maintained by City shall be excess of
Contractor's insurance and shall not contribute with it.
2. Contractor shall fax or send electronically in .pdf format a copy of insurer's cancellation
notice within two business days of receipt by Contractor.
D. Acceptability of Insurers. Insurance is to be placed with insurers with a current A.M. Best rating of
not less than ANII.
E. Evidence of Coverage. As evidence of the insurance coverages required by this Agreement,
Contractor shall furnish acceptable insurance certificates to City at the time Contractor returns the
signed Agreement. The certificate shall specify all of the parties who are additional insureds, and will
include applicable policy endorsements, and the deduction or retention level. Insuring companies or
entities are subject to City acceptance. If requested, complete copies of insurance policies shall be
provided to City. Contractor shall be financially responsible for all pertinent deductibles, self-insured
retentions, and/or self - insurance.
Construction Agreement Page 4 of 6
16. Indemnification and Hold Harmless. Contractor shall, at its sole expense, defend, indemnify and hold
harmless City and its officers, agents, and employees, from any and all claims, actions, suits, liability, loss,
costs, attorney's fees and costs of litigation, expenses, injuries, and damages of any nature whatsoever relating
to or arising out of the wrongful or negligent acts, errors or omissions in the services provided by Contractor,
Contractor's agents, subcontractors, subconsultants and employees to the fullest extent permitted by law,
subject only to the limitations provided below.
Contractor's duty to defend, indemnify and hold harmless City shall not apply to liability for damages arising
out of such services caused by or resulting from the sole negligence of City or City's agents or employees.
Contractor's duty to defend, indemnify and hold harmless City against liability for damages arising out of such
services caused by the concurrent negligence of (a) City or City's agents or employees, and (b) Contractor,
Contractor's agents, subcontractors s, subconsultants and employees, shall apply only to the extent of the
negligence of Contractor, Contractor's agents, subcontractors, subconsultants and employees.
Contractor's duty to defend, indemnify and hold City harmless shall include, as to all claims, demands, losses
and liability to which it applies, City's personnel- related costs, reasonable attorneys' fees, and the reasonable
value of any services rendered by the office of the City Attorney, outside consultant costs, court costs, fees for
collection, and all other claim- related expenses.
Contractor specifically and expressly waives any immunity that may be granted it under the Washington State
Industrial Insurance Act, Title 51 RCW. These indemnification obligations shall not be limited in any way by
any limitation on the amount or type of damages, compensation or benefits payable to or for any third party
under workers' compensation acts, disability benefit acts, or other employee benefits acts. Provided, that
Contractor's waiver of immunity by the provisions of this paragraph extends only to claims against Contractor
by City, and does not include, or extend to, any claims by Contractor's employees directly against Contractor.
Contractor hereby certifies that this indemnification provision was mutually negotiated.
17. Waiver. No officer, employee, agent or other individual acting on behalf of either party has the power,
right or authority to waive any of the conditions or provisions of this Agreement. No waiver in one instance
shall be held to be waiver of any other subsequent breach or nonperformance. All remedies afforded in this
Agreement or by law, shall be taken and construed as cumulative, and in addition to every other remedy
provided herein or by law. Failure of either party to enforce at any time any of the provisions of this
Agreement or to require at any time performance by the other party of any provision hereof shall in no way be
construed to be a waiver of such provisions nor shall it affect the validity of this Agreement or any part thereof.
18. Assignment and Delesation. Neither party shall assign, transfer, or delegate any or all of the
responsibilities of this Agreement or the benefits received hereunder without first obtaining the written consent
of the other party.
19. Confidentiality. Contractor may, from time to time, receive information which is deemed by City to be
confidential. Contractor shall not disclose such information without the prior express written consent of City
or upon order of a Court of competent jurisdiction.
20. Disputes. All disputes arising under or related to this Agreement that cannot be resolved through informal
discussion and negotiations shall be resolved by litigation filed in the Superior Court for Spokane County,
unless otherwise required by applicable federal or state law.
Construction Agreement Page 5 of 6
21. Subcontractor Responsibility. As required by RCW 39.06.020, Contractor shall verify responsibility
criteria for each first tier subcontractor and its subcontractors of any tier that hires other subcontractors shall
verify responsibility criteria for each of its subcontractors. Verification shall include that each subcontractor, at
the time of subcontract execution, meets the responsibility criteria listed in RCW 39.04.350(1) and possesses
an electrical contractor license, if required by chapter 19.28 RCW, or an elevator contractor license ifrequired
by chapter 70.87 RCW. This verification requirement must be included in every subcontract of every tier.
22. Jurisdiction and Venue. This Agreement is entered into in Spokane County, Washington. Venue shall be
in Spokane County, State of Washington.
23. Entire Agreement. This Agreement constitutes the entire and complete agreement between the parties
and supercedes any prior oral or written agreements. This Agreement may not be changed, modified or altered
except in writing signed by the Parties.
24. Anti - kickback. No officer or employee of City, having the power or duty to perform an official act or
action related to this Agreement shall have or acquire any interest in this Agreement, or have solicited,
accepted or granted a present or future gift, favor, service or other thing of value from any person with an
interest in this Agreement.
25. Business Registration. Prior to commencement of Work under this Agreement, Contractor shall register
with the City as a business.
26. Severability. If any section, sentence, clause or phrase of this Agreement should be held to be invalid for
any reason by a court of competent jurisdiction, such invalidity shall not affect the validity of any other section,
sentence, clause or phrase of this Agreement.
27. Exhibits. Exhibits attached and incorporated into this Agreement are:
1. Scope of Work
2. Insurance Endorsements
The Parties have executed this Agreement this �7 day of� , 2013.
F SP NE VALLEY:
Mike Jac o , City Manager
ATTESTi�
Contractor:
Owner
APPROVED AS TO FORM:
T
Bainbridge, City Clerk Office odhe City A 4,Wney
Construction Agreement Page 6 of 6
April 5, 2013
Parks and Recreation Department
2426 N. Discovery Place ♦ Spokane Valley, WA 99216
509.688.0300 ♦ Fax: 509.688.0188 ♦ parksandrec@spokanevalley.org
Quote Solicitation
For
City of Spokane Valley Parks & Recreation Department
• Project Title:
Terrace View Park Pool Tank Painting
Project Scope /Guidelines:
1. Cover and protect all areas not to be coated.
2. Prepare all pool surfaces for coating as per manufacturer recommendations
and standard pool practices.
3. Pressure wash and mask off as necessary.
4. Prepare and caulk seams and cracks as needed.
5. Apply specified materials as per manufacturer recommendations.
6. Workmanship to be guaranteed for a period of one year after acceptance by
the City of Spokane Valley.
7. Contractor responsible to verify and determine all measurements, quantities,
etc. to complete this project.
S. Project to begin as soon as weather permits and needs to be
completed no later than June 5, 2013.
9. Contractor will notify the Director of Parks and Recreation Department of any
work that will involve excessive noise, dust or any work that will disrupt
adjacent residences.
10. City of Spokane Valley reserves the right to stop work by contractors for any
reason deemed to be necessary.
11. Contractor will keep the jobsite clean and free of safety hazards during the
entire project.
12. If for any reason work must be stopped by contractor, the Director of Parks
and Recreation must be notified.
13. Open flames and combustibles are prohibited unless prior authorization by
the Director of Parks and Recreation.
14. Contractor is responsible for any. permits that are required for this project.
15.All applicable permits will be posted on jobsite.
16.All work must be approved by the City of Spokane Valley Parks and
Recreation Department and the YMCA prior to completion of project.
17. Contractor will be responsible for any damage done to the facility or its
contents.
• Project Location:
Terrace View Pool is located at 13525 East 24th Avenue, Spokane Valley,
Washington 99216.
Site Inspection:
Contractors interested in accessing the project site are invited to view the pool on
Friday, April 12, 2013 at 10:00 am. YMCA staff will be present to answer questions.
Bidder Requirements:
• This is a prevailing wage public works project.
• Successful contractor will need to have a current City of Spokane Valley business
license as well as being licensed and bonded.
• Contractor to have a minimum of two pool painting projects completed using
ArmorGuard paint. References may be requested.
• The insurance requirements will include naming the City of Spokane Valley as
additionally insured and having the following minimum amounts of insurance:
a. Automobile Liability - $1,000,000 per accident.
b. Commercial General Liability - $1,000,000 per occurrence and $2,000,000
general aggregate and $2,000,000 products- completed operation
aggregate limit.
• Product Specifications:
1. Main Pool — White ArmorGuard Epoxy Paint — apply two coats of 15 mil each
for a total coverage of 30 mil.
2. Main Pool Lane Lines, Targets and Depth line — Dark Grey ArmorGuard Epoxy
Paint — apply two coats of 15 mil each for a total coverage of 30 mil.
Project Contact:
Mike Stone, Director of Parks and Recreation, (509) 720 -5400
Quote Due Date:
Written quotes need to be delivered to the Spokane Valley Parks & Recreation
Department no later than 5:00 p.m. on Wednesday, April 17, 2013. The
Parks & Recreation Department is located within CenterPlace at 2426 N. Discovery
Place, Spokane Valley, Washington 99216.
Additional Information
For additional information, please contact Mike Stone, Director c
Recreation at (509) 720 -5400 or mstone(aOspoka neva I ley. org.
A N C E
DATE (MM/DDNYYY)
5/7/2013
S UPON THE CERTIFICATE HOLDER. THIS
:OVERAGE AFFORDED BY THE POLICIES
THE ISSUING INSURER(S), AUTHORIZED
1. If SUBROGATION IS WAIVED, subject to
this certificate does not confer rights to the
ipher
'3 A/C Noll: (425) 712 -3786
com
ORDING COVERAGE
NAIC #
tes Insurance Comp
XV
2CE061927 -0
/15/2013
/15/2014
EACH OCCURRENCE
$ 1,000,000
PREMISES Ea occurrence
$ 200,000
MED EXP (Any one person)
REVISION NUMBER:
THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD
INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
1�7R
TYPE OF INSURANCE
AD L
UBR
POLICY NUMBER
MM /DDY
MM %DD/YYYY
LIMITS
A
GENERAL LIABILITY
X COMMERCIAL GENERAL LIABILITY
CLAIMS -MADE X❑ OCCUR
2CE061927 -0
/15/2013
/15/2014
EACH OCCURRENCE
$ 1,000,000
PREMISES Ea occurrence
$ 200,000
MED EXP (Any one person)
$ 10,000
PERSONAL & ADV INJURY
$ 1,000,000
GENERAL AGGREGATE
$ 2,000,000
GEN'L AGGREGATE LIMIT APPLIES PER:
POLICY X PRO LOC
PRODUCTS - COMP /OP AGG
$ 2,000,000
$
AUTOMOBILE
LIABILITY
ANY AUTO
ALL OWNED SCHEDULED
AUTOS AUTOS
HIRED AUTOS X NON -OWNED
AUTOS
2CE061927 -0
/15/2013
/15/2014
Ea acB.INEDISINGLE LIMIT
1,000,000
BODILY INJURY (Per person)
$
BODILY INJURY (Per accident)
$
PROPERTY DAMAGE
Per accident
$
A
X
UMBRELLA LIAB
EXCESS LIAB
X
OCCUR
CLAIMS -MADE
01SU350889 -00
/15/2013
/15/2014
EACH OCCURRENCE
$ 5,000,000
AGGREGATE
$ 5,000,000
DED I X I RETENTIONS 10,OOC
$
A
)W EMPLOYERS' LIABILITY
ANY PROPRIETOR/PARTNER /EXECUTIVE YIN
OFFICER/MEMBER EXCLUDED?
(Mandatory in NH)
If yes, describe under
DESCRIPTION OF OPERATIONS below
NIA
Washington Stop Gap
2CE061927 -0
/15/2013
/15/2014
WC STATU- OTH-
E.L. EACH ACCIDENT
$ 1,000,000
E.L. DISEASE - EA EMPLOYEE
$ 1,000,000
E.L. DISEASE - POLICY LIMIT
$ 2,000,000
DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (Attach ACORD 101, Additional Remarks Schedule, if more space Is required)
Re: Terrace View Park Pool Tank Painting Project
The City of Spokane Valley is added as Additional Insured if required by written contract per attached
CG7680 1002 and CG8672 1002. Coverage is Primary and Non - Contributory. Per Project Aggregate applies
per attached CG2503 0509.
(509)688 -0188
City of Spokane Valley
2426 N. Discovery Place
Spokane Valley, WA 99216
MVVRL/ 40 kzu 1 VIVO)
INS025 oninnsi m
SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE
THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN
ACCORDANCE WITH THE POLICY PROVISIONS.
AUTHORIZED REPRESENTATIVE
Rucker /JAMIE
(0 1988 -2010 ACORD CORPORATION. All rights reserved.
Tha A(:r)R1'1 nnma and Innn ara raniatararl mnrka of Arr)Rr1
.. REPRINTED FROM THE ARCHIVE. THE ORIGINAL TRANSACTION MAY INCLUDE ADDITIgNALFORMS
Liberty
NortbFvest.
lF.dvl{4y Jared G..+q.
CG 76 80 10 02
THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY.
ADDITIONAL INSURED PRIMARY
COVERAGE
This endorsement modifies insurance provided under the following:
COMMERCIAL GENERAL LIABILITY COVERAGE PART
SCHEDULE
Name of Person or Organization:
Any person or organization for whom you are
required by written contract, agreement or
permit to provide a primary and non -
contributory additional insured endorsement.
(If no entry appears above, information required to complete this endorsement will be shown in the Declarations
as applicable to this endorsement.)
SECTION II — WHO IS AN INSURED is amended
to include as an additional insured the person or
organization shown in the Schedule subject to the
following provisions:
1. The additional insured is an insured but only for
liability directly resulting from:
a. your ongoing operations for the additional in-
sured whether the work is performed by you
or for you; or
b. the general supervision of your ongoing op-
erations by the additional Insured.
you. Coverage shall be limited to the extent of your
negligence or fault according to the applicable pdnci-
ples of comparative fault.
The insurance provided will not exceed the lesser of:
a. The coverage and /or limits of this policy, or
b. The coverage and /or limits required by the
contract, agreement or permit.
With respect to the insurance afforded the additional
insured, paragraph 4. of SECTION IV -- COMMER-
CIAL GENERAL LIABILITY CONDITIONS is de-
2. This insurance does not apply to: leted and replaced by the following:
a. `Bodily injury" or "property damage" arising
out of any act or omission of, or for defects
in design furnished by or for, the additional
insured or
b. "Bodily injury" or "property damage" in-
cluded within the "products - completed oper-
ations hazard."
A person's or organization's status as an additional
insured under this endorsement ends when your op-
erations for that insured are completed.
No coverage will be provided if, in the absence of this
endorsement, no liability would be imposed by law on
4. Other Insurance
a. This insurance is primary and noncontrib-
utory, and our obligations are not affected by
any other insurance where the additional in-
sured is the Named Insured, whether pri-
mary, excess, contingent, or on any other
basis; however, the defense of any claim or
"suit" must be tendered as soon as practi-
cable to all other insurers which potentially
provide insurance for such claim or "suit ".
b. This additional provision applies only to the
additional insured shown in the Schedule
and the coverage provided by this endorse-
ment.
CG 76 80 10 02 EP
AFP- META2.1 &PRINTODI- 222901531
Lilaerty
Nortlt�vest.
POLICY NUMBER:
CG 88 72 10 02
THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY.
ADDITIONAL INSURED - OWNERS, LESSEES OR
CONTRACTORS -- COMPLETED OPERATIONS
This endorsement modifies insurance provided under the following:
COMMERCIAL GENERAL LIABILITY COVERAGE PART
SCHEDULE
Name of Person or Organization:
Any person or org for whom you are required
by written contract, agreement or permit to
provide completed operations coverage.
Location and Description of Completed Operations:
Your work on all jobs at all locations for
the named person or organization.
Additional Premium:
(if no entry appears above, information required to complete this endorsement will be shown in the Declarations
as applicable to this endorsement.)
SECTION II — WHO IS AN INSURED is amended to include as an insured the person or organization shown
in the Schedule, but only to the extent you are held liable due to 'your work" at the location designated and
described in the schedule of this endorsement for that insured and included in the "product- completed
operations hazard ".
CG 86 72 10 02
Includes Copyrighted Information of ISO Properties, Inc.,
2001 with permission.
EP
C- AG•07- PRINMOl - 25WD63 -U
POLICY NUMBER:
COMMERCIAL GENERAL LIABILITY
CC's 25 03 05 09
THIS ENDORSEMENT CHANGES TH E POLICY. PLEASE READ IT CAREFULLY.
DESIGNATED CONSTRUCTION PROJECT(S)
GENERAL AGGREGATE LIMIT
This endorsement modifies insurance provided under the following:
COMMERCIAL GFNERAl LIABILITY COVERAGE PART
SCHEDULE
Designated Construction Projec{s):
ACA OF 'YOUR. CONSTRUCTION PROJECTS
LOCATED AWAY FROM PRE141SES M4NM BY OR
RENTED TO YOU
I nformation required to complete this Schedule, if not shown above, will be shown in the Declarations.
CG 25 03 OS 09 Gopyright, Insurance Services Office, Inc., 2008 Page 1 *f 2
A. For all sums which the Insured becomes legally
S. Any payments made under Coverage A for
obligated to pay as damages caused by
damages or under Coverage C for medical
'occurrences` under Section f — Coverage A, and
expenses shall reduce the Designated
for all medical expenses caused by accidents under
Construction Project General Aggregate Limit
Section I — Coverage C, which can be attributed
for that designated Construction project. Such
only to ongoing operations at a single designated
payments shall not reduce the General
construction project shown In the Schedule above;
Aggregate Limit shown in the Declarations nor
I. A separate Designated Construction Project
shall they reduce any other Designated
General Aggregate Limit applies to each
Construction Project General Aggregate Limit
designated construction project, and that limit is
far any other designated construction project
equal to the amount of the General Aggregate
shown In the Schedule above.
LlmN shown In the Declarations.
4. The limits shown In the Declarations for Each
2. The Designated Construction Project General
Occurrence, Damage To Premises Rented To
Aggregate Limit is the most we will pay for the
You and Medical Expense continue to apply.
sum of all damages under Coverage A, except
However, instead of being subject to the
damages because of `bodily injury" or "property
General Aggregate Llmll shown in the
damage" included in the "products - completed
Declarations. such limits will be subject to the
operations hazard," and for medical expenses
applicable Designated Construction Project
under Coverage C regardless of the dumber of:
General Aggregate Limit.
a. Insureds;
b. Claims made or "suits' brought; or
—
c. Persons or organizations malting claims or
ago
bringing 'suits."
CG 25 03 OS 09 Gopyright, Insurance Services Office, Inc., 2008 Page 1 *f 2
B. For all sums which the insured becomes legally
obligated to pay as damages caused by
"occurrences" under Section I — Coverage A, and
for all medical expenses caused by accidents under
Section I — Coverage C, whtoh cannot ba attributed
only to ongoing operations at a single designated
construction project shown In the Schedule above:
1. Any payments made under Coverage A for
damages or under Coverage C for medical
expenses shall reduce the amount available
under the General Aggregate Limit or the
Products -completed Operations Aggregate
Limit, whichever is applicable; and
2. Such payments shall not reduce any
Designated construction Project General
Aggregate Limit.
C. When coverage for liability arising out of the
°products - completed operations hazard" is
provided, any payments for damages because of
"bodily injury" or "property damage" included in the
'products- completed operations hazard" wiil reduce
the Products - completed Operations Aggregate
Limit, and not reduce the General Aggregate Limit
nor the Designated Construction Project General
Aggregate Limit.
D. If the applicable designated construction project
has been abandoned, decayed, or abandoned and
then restarted, or if the authorized conlracting
parties deviate from plans, blueprints, designs,
specifications or timstables, the project will Still be
deemed to be the sams construction project.
E. The provisions of Section IN — Limits Of Insurance
not otherwise modified by this endorsement shall
continue to apply as stipulated.
Page 2 of 2 Copyright, Insurance Services Office, Inc., 2008 CG 25 03 05 09